Skip to main content

Reading Refurbishment

Contact Us

Terms & Conditions

Welcome to Reading Refurbishment. These Terms & Conditions govern your use of our website and the services we provide. By accessing this website or engaging our services, you agree to comply with and be bound by these Terms & Conditions.

If you do not agree with any part of these terms, please discontinue use of our website and services.

1. About Us

Reading Refurbishment provides property refurbishment and renovation services, including but not limited to:

  • Complete Property Refurbishments
  • Loft Conversions
  • Home Extensions
  • HMO Conversions
  • Kitchen & Bathroom Renovations
  • Property Improvements
  • Project Management Services

All information provided on this website is for general information purposes only.

2. Use of the Website

By using our website, you agree that you will:

  • Use the website lawfully and responsibly.
  • Not attempt to interfere with the website’s operation or security.
  • Not copy, distribute, or reproduce website content without permission.
  • Not use the website for fraudulent or unlawful purposes.
  • Provide accurate information when submitting enquiries or appointment requests.

We reserve the right to restrict or terminate access to the website where misuse is identified.

3. Service Enquiries & Quotations

Any quotation, estimate, or project proposal provided by Reading Refurbishment is based on the information available at the time of preparation.

Quotations may be subject to:

  • Site inspections
  • Additional project requirements
  • Material availability
  • Design changes
  • Planning requirements
  • Structural findings discovered during the project

A quotation does not constitute a binding agreement until formally accepted and confirmed by both parties.

4. Appointments & Consultations

When booking an appointment through our website:

  • You must provide accurate contact information.
  • Appointment requests are subject to availability.
  • We may contact you to confirm or reschedule appointments where necessary.
  • Consultation dates and times are not guaranteed until confirmed by our team.

We reserve the right to amend appointment schedules due to unforeseen circumstances.

5. Project Scope & Variations

The scope of any refurbishment project will be defined within the agreed quotation, proposal, contract, or written agreement.

If additional work is requested during the project:

  • Additional costs may apply.
  • Project timelines may be affected.
  • Written approval may be required before additional work is undertaken.

Any changes requested after project commencement may result in revised pricing and completion schedules.

6. Planning Permission & Approvals

Certain projects may require:

  • Planning Permission
  • Building Regulations Approval
  • Structural Engineering Input
  • Party Wall Agreements
  • Local Authority Approvals
  • HMO Licensing Requirements

Responsibility for obtaining relevant approvals will be determined within the project agreement.

Reading Refurbishment may assist with coordination and guidance but cannot guarantee approval from any third-party authority.

7. Project Timelines

Estimated project durations are provided as guidance only.

Completion dates may be affected by:

  • Weather conditions
  • Material shortages
  • Supplier delays
  • Regulatory approvals
  • Structural discoveries
  • Client-requested changes
  • Circumstances outside our reasonable control

While we strive to meet agreed schedules, we cannot guarantee exact completion dates.

8. Payments

Payment terms will be outlined within the relevant quotation, proposal, or project agreement.

Payments may be required:

  • Before work commences
  • At agreed project milestones
  • Upon completion of specific stages
  • Upon final project completion

Failure to make payments in accordance with agreed terms may result in delays, suspension of work, or additional charges where legally permitted.

9. Client Responsibilities

Clients agree to:

  • Provide accurate information regarding the property and project.
  • Allow reasonable access to the property when required.
  • Make decisions and approvals within agreed timescales.
  • Ensure relevant permissions are obtained where required.
  • Communicate any concerns or changes promptly.

Delays caused by client actions or omissions may impact project schedules and costs.

10. Intellectual Property

All website content, including:

  • Text
  • Graphics
  • Images
  • Logos
  • Branding
  • Layouts
  • Design Elements

remain the property of Reading Refurbishment or the respective content owner unless otherwise stated.

No content may be copied, reproduced, distributed, or used without prior written permission.

11. Website Content Disclaimer

While we aim to keep information accurate and up to date, we make no guarantees regarding:

  • Accuracy
  • Completeness
  • Reliability
  • Suitability
  • Availability

of the information presented on this website.

Website content may be updated, modified, or removed without notice.

12. Limitation of Liability

To the fullest extent permitted by law, Reading Refurbishment shall not be liable for:

  • Indirect losses
  • Consequential losses
  • Business interruption
  • Loss of profits
  • Loss of opportunity
  • Data loss
  • Website downtime

arising from the use of this website or reliance on information provided.

Nothing in these Terms & Conditions excludes liability where exclusion is not permitted by law.

13. Third-Party Links

Our website may contain links to third-party websites for information or convenience.

We do not:

  • Endorse third-party content
  • Control third-party websites
  • Accept responsibility for third-party policies or practices

Users access external websites at their own risk.

14. Privacy & Data Protection

Your use of this website is also governed by our Privacy Policy.

By submitting information through our website, you acknowledge that your information may be processed in accordance with our Privacy Policy.

We are committed to handling personal information responsibly and in accordance with applicable data protection laws.

15. Force Majeure

We shall not be held responsible for delays or failures caused by events beyond our reasonable control, including but not limited to:

  • Natural disasters
  • Severe weather
  • Supply chain disruptions
  • Labour shortages
  • Government restrictions
  • Utility failures
  • Industrial disputes

Such events may affect project schedules and service delivery.

16. Changes to These Terms

We reserve the right to update or amend these Terms & Conditions at any time.

Any changes will be published on this page with an updated revision date.

Continued use of the website following changes constitutes acceptance of the updated terms.

17. Governing Law

These Terms & Conditions shall be governed by and interpreted in accordance with the laws of England and Wales.

Any disputes arising from the use of this website or our services shall be subject to the exclusive jurisdiction of the courts of England and Wales.

18. Contact Information

If you have any questions regarding these Terms & Conditions, please contact us.

Reading Refurbishment
Email: info@readingrefurbishments.co.uk
Phone: 0118 900 0000
Address: 12 Station Road, Reading Berkshire, RG1 1JX